common / Legals

Public Notices

NOTICE TO CONTRACTORS
The North Dakota Department of Transportation
(NDDOT) will receive bids for the construction of
the following project(s):
Job No.: 33
Project No(s).: IM-6-029(140)183 & IM-6-
029(141)183
Length: 18.361
Type: CHIP SEAL
County(s): WALSH & PEMBINA Cos
Location: I-29 FROM 3 MILES SOUTH OF
DRAYTON, NORTH TO 1 MILE NORTH OF CMC
3424 AT BOWESMONT, NB & I-29 FROM 3 MILES
SOUTH OF DRAYTON TO NORTH OF JCT ND 66,
SB
Bids will be received via the Bid Express online bidding exchange at www.bidx.com until
09:30AM, April 12, 2019. Bids will be opened at
that time at the NDDOT building on the capitol
grounds in Bismarck and the bid results will be
distributed and posted online at https://www.dot.
nd.gov/business/bidinfo.htm approximately 30
minutes after bids are opened.
The proposal forms, plans, and specifications
are available on the NDDOT website at http://
www.dot.nd.gov and may be inspected at the
Construction Services Division, 608 East Boulevard
Avenue, Bismarck, North Dakota.
All bidders not currently prequalified with NDDOT
must submit a Contractor’s Prequalification
Statement (SFN 9384) to the Department at least
ten (10) business days prior to the bid opening.
The form can be found on the NDDOT website.
Online prequalification is also available.
NDDOT reserves the right to reject any and all
proposals, waive technicalities, or to accept such
as may be determined in the best interests of the
state.
For disability/language assistance, call 701-328-
2978.
Requested by:
Thomas K. Sorel, Director
North Dakota Department of Transportation
(March 20, 2019)
“ORDINANCE NO. 326
AN ORDINANCE TO AMEND SECTION
12-1 OF ARTICLE I, CHAPTER 12 OF THE
CODE OF ORDINANCES OF THE CITY OF
GRAFTON, NORTH DAKOTA RELATING
TO DEFINITIONS OF HEALTH AND
SANITATION
SECTION 2. PENALTY PROVISIONS.
Any person, firm, or corporation, violating any
provisions of this ordinance shall be deemed guilty
of a misdemeanor, and upon conviction thereof,
shall be subject to a fine, or imprisonment, or
both, in accordance with the general penalty
provision of this Code (§1-14). Each day such
violation is committed, or permitted to continue,
shall constitute a separate offense, and shall be
punished as such hereunder.
Connie A. Johnson
City Auditor-Treasurer”
(March 20, 2019)

STATE OF NORTH DAKOTA IN DISTRICT COURT
COUNTY OF WALSH NORTHEAST JUDICIAL
DISTRICT
CHS Capital, LLC, Case No
50-2017-CV-00005
Plaintiff,
v. NOTICE OF
EXECUTION SALE
Louis L. Slominski and
Louis L. Slominski, Jr.,
Defendants.
[¶1] Notice is hereby given that by virtue of a
Judgment and decree rendered, entered and
docketed in the office of the Clerk of District
Court on the 4th day of May, 2017 in favor of the
Plaintiff and against the Defendants in the aboveentitled action, which Judgment it was adjudged
that there was due and owing to the Plaintiff in
the original sum of $1,521,507.91, and by virtue
of an execution to me issued out of the office
of the Clerk of said Court, pursuant to which
I levied upon the Defendant Louis L. Slominski
(Sr.)’s interest in certain real estate, I will sell said
Defendant’s interest in the real estate situated in
Walsh County hereinafter described to the highest
bidder for cash, at public auction at the front door
of the Courthouse in the City of Grafton, Walsh
County, North Dakota, on the 10th day of April,
2019 at 10:00 a.m., of that day, to satisfy the
amount due to the date of sale, or so much thereof
as the proceeds of said sale applicable thereto will
satisfy.
[¶2] The current balance due on the Judgment for
which execution has been issued is the principal
sum of $1,368,035.70, plus sheriff’s fees and
commissions, post-judgment costs and interest
accruing at the legal rate from and after April 11,
2018.
[¶3] The real estate to be sold as aforesaid, located
in the County of Walsh, State of North Dakota, is
described as follows:
N½NW¼ of Section 17, Township 156
North, Range 52 West of the 5th P.M.;
and
S½NW¼ of Section 17, Township 156
North, Range 52 West of the 5th P.M.;
and
A tract in the NE¼ of Section 36,
Township 156 North, Range 53 West
of the 5th P.M., described as follows:

Commencing at the SE corner of said
Section 36, thence north on an assumed
bearing along the East line of said
Section, 3110.00 feet to the point of
beginning; thence west 565.00 feet;
thence north 627.64 feet; thence N
50"58'34" E, 87.06 feet; thence east
152.05 feet; thence south 460.40 feet;
thence east to a point on the East line
of said Section, 336.00 feet; thence
south along the East line of said
Section, 222.00 feet to the point of
beginning; and
E½NW¼ of Section 19, Township 155
North, Range 51 West of the 5th P.M.;
and
SW¼ of Section 5, Township 156 North,
Range 52 West of the 5th P.M.; and
W½NE¼ of Section 24, Township 155
North, Range 52 West of the 5th P.M.;
and
N½SE¼ of Section 10, Township 155
North, Range 52 West of the 5th P.M.;
and
Government Lots 3 and 4, S½NW¼ and
SW¼, comprising the W½, LESS parcel
east of the Forest River in the SE¼SW¼
of said SW¼, Section 4, Township 155
North, Range 52 West of the 5th P.M.,
AND LESS a strip of land 3 rods wide
in said Government Lots conveyed in
Book 12 Deeds, page 161.
Dated at Grafton, North Dakota, this 26th day
of February, 2019.
THE SHERIFF OF WALSH COUNTY
By: /s/ Lisa Graham
Lisa Graham, Deputy Sheriff
Walsh County, North Dakota
Jon R. Brakke (#03554)
jbrakke@vogellaw.com
VOGEL LAW FIRM
218 NP Avenue
PO Box 1389
Fargo, ND 58107-1389
Telephone: 701.237.6983
Facsimile: 218.236.9873
Attorneys for Plaintiff CHS Capital, LLC
(March 6, 13 & 20, 2019)

SECTION 1.1
ADVERTISEMENT FOR BIDS
DRAIN 87 – PHASE 2
WALSH COUNTY WATER RESOURCE
DISTRICT
COUNTY OF WALSH, NORTH DAKOTA
Sealed bids will be received by the Walsh County
Water Resource District, at the office of the Walsh
County Water Resource District, Walsh County
Courthouse, 600 Cooper Avenue, Grafton, ND
58237, until 10:00 AM CT, April 16th, 2019, at
which time they will be publicly opened and read
aloud for the furnishing of labor, equipment, skill,
and any materials required for Drain 87 – Phase 2
and incidental items in and for the Walsh County
Water Resource District, as is more fully described
and set forth in the plans and specifications
therefore, which will be made available as specified
below.
Bids shall be upon cash payment on the following
estimated quantities and types of work:
The Drain 87 – Phase 2 project will consist of
approximately 11.5 miles of ditch construction and
excavation. The project will have approximately
445,000 CY of earthwork which includes
excavation and topsoil, reinforced concrete
box culverts, CMP and CMPA culverts, riprap
installation, drainage improvements, and related
work. Refer to the Schedule of Work shown in
the Proposal found in the bid package for the
complete list of bid items and quantities.
Paper copies of the contract documents will be on
file and may be examined at the following:
Walsh County Water Board, Walsh County
Courthouse, 600 Cooper Avenue, Grafton, ND
58237
Houston Engineering, Inc., 1401 21st Avenue
North, Fargo, ND
Copies of the contract documents and additional
project information may also be viewed free of
charge online at www.houstoneng.com by clicking
on the “Bid Info” tab, or downloaded for a nonrefundable fee of $25. Paper copies of the plans
and specifications may be obtained from the
office of Houston Engineering, Inc., 1401 21st
Avenue North, Fargo, ND 58102, upon payment
of $50.00, non-refundable. Please contact us at
701-237-5065 if you have any questions.
All bids are to be submitted on the basis of cash
payment for the work and materials, and each
bid shall be accompanied by a separate envelope
containing the contractor’s license and bid security.
The bid security must be in a sum equal to five
percent (5%) of the full amount of the bid and
must be in the form of a bidder’s bond. A bidder’s
bond must be executed by the bidder as principal
and by a surety company authorized to do business
in this state, conditioned that if the principal’s bid
be accepted and the contract awarded to the
principal, the principal, within ten (10) days after
notice of award, will execute and affect a contract
in accordance with the terms of the bid and the bid
bond as required by the laws of the State of North
Dakota and the regulations and determinations
of the governing body. If a successful bidder
does not execute a contract within ten (10) days
allowed, the bidder’s bond must be forfeited to
the governing body and the project awarded to
the next lowest responsible bidder.
All bidders must be licensed for the full amount of
the bid as required by Section 430707 and 43-07-
12 of the North Dakota Century Code.
The successful Bidder will be required to furnish
Contract Performance and Payment Bonds in the
full amount of the contract.
Contracts shall be awarded on the basis of the
low bid submitted by a responsible and responsive
bidder for the aggregate sum of all bid items. A
single contract will be awarded for the work.
All bids will be contained in a sealed envelope, as
above provided; plainly marked showing that such
envelope contains a bid for the above project. In
addition, the bidder shall fixed to the exterior of
such envelope the following information:
1. The work covered by the bidder
2. The name of the bidder
3. Separate envelope containing bid bond,
a copy of North Dakota Contractor’s
License or certificate of renewal, and
Acknowledgement of each Addenda individually. As an alternative to Acknowledgement of the
Addenda in the separate envelope containing
the bid bond and a copy of the North Dakota
Contractor’s License or certificate of renewal, each
individual Addenda may be acknowledged on the
exterior of the envelope containing bid bond and
a copy of North Dakota Contractor’s License or
certificate of renewal.
No Bid will be read or considered which does not
fully comply with the above provisions as to Bond
and licenses and any deficient Bid submitted will be
resealed and returned to the Bidder immediately.
All work included in the Contract shall, with the
exception of Seeding & Mulching, be completed by
December 1st, 2019. Seeding & Mulching shall
be completed by June 15th, 2020.
The Owner reserves the right to reject any and all
bids and rebid the project until a satisfactory bid
is received, to waive any informality in any bid, to
hold all bids for a period not to exceed 60 days
from the date of opening bids, and to accept the
bid deemed most favorable to the interest of the
Owner. After the bid opening, the Owner reserves
the right to request up to three (3) references
from the lowest three bidders of similar work
completed within the last five (5) years. References
shall include the owners of recently completed
work. The lowest three bidders must provide
the references as requested by the Owner, or
justification why references were not provided.
If the Contractor fails to complete the work
according to the terms of the Contract within the
time specified, he shall pay the Owner the sum of
$1,000.00 per calendar day as liquidated damages.
The Owner reserves the right to withhold Progress
Payments and/or Final Payment until such time
that all liquidated damages have been paid by
the Contractor. The Owner shall deduct liquidated
damages from Progress Payments and/or Final
Payment if the Contractor does not pay liquidated
damages.
Dated this 11th day of March 2019.
WALSH COUNTY WATER
RESOURCE DISTRICT
COUNTY OF WALSH,
NORTH DAKOTA
s/Daryl Campbell
Chairman
(March 20, 27, April 3 & 10, 2019)

GRAFTON PUBLIC SCHOOL DISTRICT #3
1548 SCHOOL ROAD
GRAFTON, NORTH DAKOTA 58237
REGULAR SCHOOL BOARD MEETING
MONDAY, FEBRUARY 11, 2019
A regular meeting of the Grafton Public School
Board was held on Monday, February 11, 2019
at 8:00 a.m. in the Board Conference Room at
the Grafton High School, 1548 School Road,
Grafton, North Dakota. Board Members present
were Greg Feltman, Scott LeClerc, Sharon Lipsh,
Donald Suda, Jennifer Thompson, and Tom
Torkelson (8:03). Board Member Barry Kingsbury
was absent.
President Suda called the meeting to order.
No changes to the agenda were noted.
It was moved by Feltman, seconded by Thompson,
and carried unanimously, that the minutes of the
Regular School Board Meeting of January 14,
2019 be approved, that the payroll be approved,
and that the bills on the attached listing totaling
$970,466.24 be approved. It was moved
by Feltman, seconded by Lipsh, and carried
unanimously, that the Fund Balance, Expenditures
& Revenue reports be approved. Torkelson arrived
at this time.
It was moved by Torkelson, seconded by LeClerc,
and carried unanimously by roll call vote that the
teacher-signed, board-approved Agreements to
Reduction-In-Force nonrenewal offer for Lana
Lindell (1.0 FTE) and Tracy Forbord (.5 FTE) due
to uncertainty of funding by the SRCL Grant be
accepted.
It was moved by Thompson, seconded by Lipsh,
and carried unanimously by roll call vote to
approve the petition for recognition as follows:
“Pursuant to NDCC 15.1-16-10 the Grafton
Public School District recognizes as the
appropriate negotiating unit all employees
licensed to teach by the ESPB or approved to
teach by the ESPB and employed primarily as a
classroom teacher.”
It was moved by Feltman, seconded by LeClerc,
and carried unanimously by roll call vote to
approve the Energy Grant for $10,475.
It was moved by LeClerc, seconded by Lipsh, and
carried unanimously by roll call vote to hold the
School Board election in the Grafton High School
Commons on Tuesday, June 11, 2019 from 9:00
a.m. to 7:00 p.m. It was moved by Torkelson,
seconded by LeClerc, and carried unanimously by
roll call vote to set the June School Board Meeting
for Monday, June 16, 2019 at 5:30 p.m. as
determined by NDCC 15.1-09-15.
Adjournment.
ATTEST:
___________________ ___________________
Donald Suda, President Cathi Heuchert,
Business Manager
The list of bills presented to the School Board
on February 11, 2019: 4Imprint 252.14; Aflac
Group Insurance 203.58; Albrecht, Darren
91.90; Altru Health System 20.00; Amazon.
com 1,107.87; American Family Life Assurance
4,924.68; Americinn Motel & Suites 1,353.60;
Atkins, Blake 253.80; Auto Value 52.30; Baldwin,
Stephanie 80.92; Beaudry, Brandon 283.04; Blue
Cross/Blue Shield of ND 55,807.10; Carlson,
Todd 125.20; Caseys 140.35; Cenex Ewing
23.69; Cobblestone Inn 7 Suites Harvey 507.60;
Cole Papers, Inc. 4,043.77; Crookston High
School 100.00; Culinex 517.48; Curran, Tim
414.72; Currie, Andy 136.06; Custom 365 LLP
2,505.00; Dean Foods NC 1,568.65; Dept. of
Public Instruction 114.76; Durgin, Doug 283.04;
Ebay 337.62; Ecolab Pest Elimination 315.86;
Educators Benefit Consultants, LLC 4,966.30;
Elliot, Dave 283.04; Eventbrite 75.58; Exxon
93.28; Fiechtner, Matt 253.80; Follett Educational
Services 35.00; Food Services of America 795.19;
Ford, Mitch 291.76; Friendship, Inc. 244.40;
Global Safety Network 341.40; Goll, Robert
235.00; Grafton Auto Electric 277.97; Grafton
Chamber of Commerce 235.00; Grafton Parks
& Recreation 13,760.00; Grafton True Value
Hardware 303.78; Grainger 1,151.25; Heartland
Eye Care 694.00; Hell, Matt 235.00; Helland, Gary
176.66; Hills, Ryan 290.00; Hillyard/Hutchinson
3,336.06; Hilton Hotel 125.98; Home of Economy
177.51; Houdek, Justin 125.00; Houdek,
Matthew 125.00; Hugo’s #10 1,672.09; Hylden,
Isaiah 282.56; Innovative Office Solutions LLC
339.09; Jaeger Sports 536.95; Jaymar Business
Forms, Inc. 428.85; JL Beers 15.01; Johnson
Controls 515.51; Johnson, Douglas 10.50;
Keva Planks Education 375.00; Kittelson, Trevor
339.32; Kleber, Mitchell 313.80; Kulas, Joseph
125.20; Lake Region State College 1,588.92;
Lakeshore Learning Materials 224.16; Lindberg,
Susan 300.00; Loing, Jacob 165.06; Marco-
Fargo 5,343.44; MCI Service Parts Inc 248.63;
Menards 179.89; Midcontinent Communications
952.13; Misialek, Kirk 166.22; Montana Dakota
Utilities 6,998.51; Morgan Publishing Inc. 73.50;
Municipal Utilities 19,761.99; Music Theatre
International 3,590.00; Napa Auto Parts 302.89;
Naylor, Dana 283.04; Naylor, Daniel 283.04; ND
Public Employees Retirement 19,862.57; ND
Teachers Fund for Retirement 84,664.70; ND
United 1,962.37; Network Center Inc. 449.00;
Nordstrom, Amy 79.90; North Dakota Counseling
Assn 203.50; North Valley Career-Tech Center
78,124.00; Northwest Iron Fireman, Inc. 1,187.66;
O’Connell, Todd 156.90; Obregon, Sandra
25.09; Oby, Lisa 9.09; Olson, Jill 22.76; Oriental
Trading Company 190.54; Pan-O-Gold Baking
Co. 498.84; Paxton, Lucinda 6,000.00; Pepsi
Americas 2,491.92; Perma-Bound 14.20; Pioneer
Mutual 15.00; Pitney Bowes Global Financial Svcs
LLC 185.49; Postmaster 300.00; PSAT/NMSQT
168.00; Pushsave 100.00; Qualifiedhardware.
com 694.00; Radisson Hotel Bismarck 1,692.00;
Rensvold, Doug 206.82; Rice, Randy 391.38;
Rock’s Electric Construction, Inc. 306.06; Sam’s
Club 1,002.58; Scenario Learning, LLC 1,620.00;
Schaan, Vince 235.00; Scholastic Book Clubs, Inc.
73.00; School Specialty Inc. 57.73; Schumacher
& Sons 4,189.23; Schwab, Brady 117.50; Scott,
David 100.00; Shopko Stores Operating Co., LLC
132.83; Simonson Station Stores, Inc. 120.20;
Spoor, Jarrod 117.50; Strand Theatre 45.00;
Sundre, Zachary 117.50; Super America 17.85;
Taco Johns 10.18; Teal’s Market 100.20; Tietz,
Craig 126.90; Tractor Supply Co 19.99; United
Airlines 288.20; Unity Medical Center 410.00;
Upper Valley Special Ed. Unit 91,177.25; US Food
Services 12,873.16; USAble Life 15.00; Verizon
Wireless 616.10; Vex Robotics Inc 450.00; Volk,
Rodney 389.20; Wageworks Inc. 122.00; Walsh/
Pembina Administrators 533.11; Welch, Sandi
163.77; Direct Deposits Payroll 387,039.66;
Payroll Tax Deposits 118,575.82; Grand Total
$970,466.24.
(March 20, 2019)

SECTION 00 1113 - ADVERTISEMENT FOR BIDS
The North Dakota Department of Human Services,
Life Skills and Transition Center, 701 West 6th
Street, Grafton, North Dakota 58237, Attn: Mark
Burns, will receive sealed bids, in duplicate, until
1:00 p.m., CT, Thursday, April 11, 2019, in the
Nutrition Services Building (809 West Cedar Drive,
Grafton, ND 58237), West Conference Center, on
the Life Skills and Transition Center campus for
Generator Transfer Switch Replacement Contract
for the replacement of existing automatic transfer
switch, and associated other work, as described in
Contract Documents prepared by EAPC Architects
Engineers, Grand Forks, North Dakota, Engineer.
All qualified proposals will be publicly opened and
read aloud at this time. A bid tab will be provided.
This project consists of the removal of two
automatic transfer switches along with associated
controls, and the installation of a single automatic
transfer switch to replace transfer switches being
removed. Also included is the installation of a
new CT cabinet with service disconnect. As this
is a controlled access facility, security measures and
coordination with State’s staff shall be required
at all times. Substantial completion is required
to be no later than September 19, 2019. Final
completion is required to be no later than October
17, 2019.
Any bid may be withdrawn prior to the above
scheduled time for opening of the bids or the
authorized postponement thereof. Any bid
received after the time and date specified will
not be considered. Bidder shall assume full
responsibility for timely delivery of their proposal
to the State.
A Mandatory, Pre-Bid Conference will be held
at 1:00 p.m., CT, on Tuesday, April 2, 2019, in the
Nutrition Services Building (809 West Cedar Drive,
Grafton, ND 58237), West Conference Center,
on the Life Skills and Transition Center campus.
Interested firms will be provided with an overview
of the proposed project. After the conference,
interested firms will be able to tour the project
site to obtain first-hand knowledge of services
to be performed, to review existing conditions,
and to obtain independent measurements and
observations, prior to submitting a bid. No other
observation of the project site will be provided for
this project.
Bids must be submitted on original copies of the
Bid Form in the project specifications and must be
accompanied by a separate envelope containing
a Bidder’s Bond in a sum equal to five percent of
the full amount of the Bid executed by the Bidder
as Principal and by a Surety Company authorized
to do business in this State, conditioned that if
the Principal’s Bid be accepted and a Contract be
awarded to the Principal, the Principal, within 10
days after notice of award, will execute and effect
a Contract in accordance with the terms of the
Principal’s Bid and a Contractor’s Bond as required
by law and the regulations and determinations of
the Life Skills and Transition Center. The successful
bidder will be required to furnish a Payment and
Performance Bond in the full amount of the
contract.
All Bidders must be licensed for the highest
amount of their Bid, as provided by Section 43-
07-05 of ND Century Code. Bidders must hold a
North Dakota Contractor’s License and carry North
Dakota Workers’ Compensation Insurance as
required by law. The required bid bond envelope
shall also contain a copy of the Contractor’s
License or Certificate of Renewal thereof issued by
the Secretary of State as required by law.
Complete digital project bidding documents
are available at www.questcdn.com. You may
download the digital plan documents for $15.00
by inputting Quest project #6225116 on the
website’s Project Search page. Please contact
QuestCDN.com at 952-233-1632 or info@
questcdn.com for assistance in free membership
registration, downloading, and working with this
digital project information.
Bidding Documents may be examined at the office
of the Engineer, EAPC Architects Engineers, 3100
Demers Avenue, Grand Forks, ND 58201, and
the following Builders Exchanges: Minot Builders
Exchange, Fargo-Moorhead Builders Exchange,
Grand Forks Builders Exchanges, Minnesota
Builders Exchange, Construction Plans Exchange,
Sioux Falls Builders Exchanges, Aberdeen Builders
Exchange, Construction Industry Center, CMD
Group, Dodge Data & Analytics; and the Life Skills
and Transition Center Plant Services Director.
Contractors may request an electronic copy of the
Bidding Documents from carol.englund@eapc.
net, no fee will be required. Hard Copies may be
obtained from the EAPC Architects Engineers,
3100 Demers Avenue, Grand Forks, ND, 58201,
by providing names, address, phone number,
and email contact information. A non-refundable
fee of $25.00 is required for each set of printed
Bidding Documents. Bidders must allow EAPC
one day to develop bid documents after request
to provide.
Each Bidder is responsible for reading and
becoming thoroughly familiar with the project’s
Contract and Bidding Documents. Failure of any
Bidder to understand the bidding or contract
documents does not relieve any Bidder from any
obligation in respect to their Bid.
All questions seeking clarification or interpretation
of the bidding or contract documents must be in
writing and directed to Travor Fredrickson, EAPC
Architects Engineers, 3100 Demers Avenue,
Grand Forks, ND 58201, and cite LS006 Generator
Transfer Switch Replacement. Written questions
must be received by 5:00 p.m., CT, Friday, April
5, 2019, to allow issuance of any necessary
amendments.
The Life Skills and Transition Center reserves the
right to hold all bids for a period of 60 days after
the day fixed for the opening of the bids, and the
right to reject any or all bids and to waive any
informalities.
No Bid will be read or considered which does not
fully comply with the above provisions as to Bond
and Licenses, and any deficient Bid submitted
will be resealed and returned to the Bidder
immediately.
Published by authority of the Life Skills and
Transition Center, Grafton, North Dakota
Susan Foerster, Superintendent
Grafton, North Dakota
Dated this 20th Day of March, 2019
(March 20, 27, & April 3, 2019)

Minto Public School District #20
Filing for School Board Election Deadline
Minto School Board annual election will
be held Tuesday, June 11, 2019 at the Minto
School from 9:00 am to 7:00 pm.
Notice is hereby given that the filing
deadline is Monday, April 8, 2019, at 4:00 pm.
Three 3-term positions up for election:
one member within the limits of the incorporated City of Minto, one member East of
Highway 81 and outside the limits of the
incorporated city of Minto, and one member
West of Highway 81 and outside the limits of
the incorporated city of Minto.
Applications are available on the school
website and at the school office between
the hours of 8:00 a.m. and 4:00 p.m. Please
return applications to district business manager. (March 20, 27 & April 3, 2019)
“REQUEST FOR BID
NATURAL GAS GENERATORS
The City of Grafton requests bids for three 50 kw
natural gas generators and one 200 kw natural
gas generator to be delivered to Grafton, ND. Bid
information is available from the City Auditor at
City Hall, 5 East 4th Street, Grafton, ND 58237
or by contacting City Auditor at cjohnson@
graftongov.com or 701-352-1561.
Bids shall be submitted in a sealed envelope
plainly marked “Bid for Generators”, addressed
to “City Auditor, PO Box 578, 5 East 4th Street,
Grafton, ND 58237”. Bids must be received by
the City Auditor by 2:00 p.m. Wednesday, April 3,
2019, at which time they will be publicly opened
and read aloud.
The City reserves the right to reject any and all
bids or parts of bids, to waive irregularities, to
hold all bids for a period not to exceed 30 days
from the date of opening bids, and to accept the
bid deemed most favorable to the City.
Connie A Johnson
City Auditor”
(March 13, 20 & 27, 2019)

Return to top